Contact Us
The Best JUDGEMENT Search Engine...
The Best JUDGEMENT Search Engine...
Consumer Protection Act, 1986; Force Majeure -- Complaint against developer for delayed possession – Developer took the plea of Force Majeure on the ground that Authority failed to supply electricity in time – Documents revealed that the Developer made payment to Authority for electric at a much later date -- The plea of Force Majeure circumstances does not stand – Award for registration in favour of the complainant along the penal interest and compensation.
Consumer Protection Act, 1986; S.24A – Limitation to lodge consumer complaint – Delay of more than two years since arising of cause of action – Held: after accepting almost the entire consideration amount it is bounden duty on the part of developer/builder to deliver possession and to execute the sale deed and unless it is done, the cause of action is a continuous one.
